The mission of the Connecticut Judicial Branch is to serve the interests of justice and the public by resolving matters brought before it in a fair, timely, efficient and open manner.

Land Use Appellate Court Opinion - 8/15/2016

by Zigadto, Janet

 

AC37736 - Diamond 67, LLC v. Oatis (Vexatious litigation; "The plaintiff . . . appeals from the summary judgment rendered by the trial court in favor of the defendants . . . The plaintiff sought to develop a Home Depot store in the town of Vernon that the defendants, a group of concerned citizens and their attorneys, opposed for environmental reasons. Certain defendants, allegedly acting with the support of their codefendants, thus sought to intervene in various administrative and mandamus actions between the plaintiff and the Planning and Zoning Commission of the Town of Vernon (planning and zoning commission). Thereafter, the plaintiff brought this action, sounding in vexatious litigation, claiming that the defendants' conduct in intervening or supporting other defendants' interventions in the planning and zoning actions, and their appeals from the denials thereof, had delayed it in obtaining the necessary final approval from the planning and zoning commission. The plaintiff claimed that because those appeals delayed the approval of the Home Depot development project by the planning and zoning commission until after the deadline agreed to for that purpose in the plaintiff's agreement with Home Depot, Home Depot abandoned the development project to the plaintiff's great financial loss. The trial court granted all of the defendants' motions for summary judgment on the ground that the plaintiff could not establish that the defendants' actions had caused Home Depot to abandon the development project, or thus to sustain any compensable losses. The plaintiff appeals, claiming that genuine issues of material fact remain as to the causation of damages. The defendants argue that summary judgment was appropriately rendered, and raise various alternative grounds for affirmance as well. We agree with the plaintiff that summary judgment was improperly granted, and decline to affirm the court's judgment on any of the alternative grounds proposed by the defendants.")